These Standard Terms and Conditions of Sale of StandardAero "StandardAero", together with the terms of sale set forth in our signed
proposal "Proposal" submitted to you, will be the only terms of sale applicable to our provision of repair, overhaul or servicing "Services"
of your aircraft and parts thereof "Equipment" described in the Proposal and will comprise the entire agreement "Agreement" for these
Services. In this Agreement "you" and "your" refer to the customer identified in the Proposal and "we", "us" and "our" refer to StandardAero.
General Procedure.
We will perform Services on your Equipment as required in
your Workscope and stated in the attached Proposal. Services will be in
accordance with our standard commercial practices and may, with your
concurrence, include Designated Engineering Representative
"DER" repairs on
non-rotating parts and assemblies and the use of PMA parts. We may use parts
from our rotable parts inventory to replace your repairable parts which will be
repaired by us at your expense. If such removed parts are later scrapped,
condemned or determined to be non-repairable, the parts will be disposed of at no
expense to you and you will pay the list price for the replacement part, less any
applicable exchange fee previously paid. Title to parts and material furnished by
us will pass to you upon incorporation in the Equipment and, simultaneously, title to
the parts replaced will pass to us. At Redelivery, we will provide you copies of all
work records required by, as applicable, the FAA, JAA, CAA or other equivalent
aviation authority (each, an
"Approved Aviation Authority" which we agree in
writing.
Governmental Authorization.
You will be the importer/exporter of record of
the Equipment and, unless we otherwise agree in writing, you will be
responsible for obtaining all necessary import/export licenses, permits and other
required authorizations. All Delivered items (including technical data) shall at
all times be subject to U.S. Export Regulations, International Traffic in Arms
Regulations of the U.S., and applicable U.S. Customs Regulations. You will not
dispose of USA-origin items furnished by us (including technical data) other
than in and to the country of ultimate destination specified in the Proposal,
government license(s), and authorization(s), except as law and regulation
permit.
Taxes.
You agree to pay all taxes, duties, fees, charges or assessments of any
nature (but excluding income taxes) assessed or levied in connection with
performance of this Agreement.
Prices/Payment.
Our prices for Services are stated in U.S. Dollars and shall be at the rates quoted
to you in the Proposal. Any Service provided that is not priced in the Proposal shall
be charged in accordance with our standard pricing. All invoices are due prior to Redelivery
of the repaired Equipment and shall be paid by wire transfer to our bank account, immediately
available for use and without set-off. If your account becomes delinquent, you will grant us
commercially acceptable assurances of payment. You will pay us one and one-half percentage (1.5%)
points interest per month for all payments past due.
Excusable Delay.
You will excuse us from, and we will not be liable for, any
delay in our performance due to causes beyond our reasonable control and, in
the event of such delay, we may invoice you for all completed Services. If you
cause a delay, your Equipment may be removed from Service, which may result
in a greater than day-for-day delay in the completion of Services.
Warranty.
We warrant that for a period of 90 days after the date of
Redelivery the work performed on the Equipment will be free from defects in
workmanship and conform to final specifications, plans, and drawings that the
parties have agreed in writing to be a part of this Agreement. You will send us
written notice of a defect within thirty (30) days of discovering it. If we
reasonably determine that the work performed does not meet this warranty then
we will promptly, at our option, either (a) repair the defective work, (b) replace
the defective item, or (c) refund the repair price allocable to the defective
work. The warranty period on any such repaired or replaced item will be the
unexpired portion of the warranty on the initially repaired item. You will send
the defective item, freight prepaid, to the location we specify. We will
reimburse reasonable freight charges you incur for transportation for repairs
covered by this warranty. This warranty is exclusive and in lieu of all other
warranties including warranties of merchantability and fitness for a
particular purpose. We will not be responsible for incidental, resultant or
consequential damages. This warranty is not assignable without our written
consent and is applicable only if, following Redelivery, the Equipment (a) has
been transported, stored, installed, operated, handled, maintained and repaired
in accordance with Airworthiness Directives and the then-current
recommendations of the Equipment manufacturer as stated in its manuals,
Service Bulletins or written instructions; (b) has not been altered, modified or
repaired by anyone other than us; and (c) has not been subjected to accident,
misuse, abuse or neglect.
Indemnity. By StandardAero.
We shall indemnify, defend, save, and hold
harmless Customer and its Affiliates, Parent, subsidiaries and their respective
directors, officers, and employees from and against any and all
responsibilities, liabilities, claims, demands, suits, judgments, losses, damages,
costs, and expenses for any loss of, damage to, or destruction of any property
(including the Engines) or any injury to or death of any person arising from
StandardAero's negligence, misconduct or performance of its
obligations under this Agreement; provided, however, StandardAero
AVIATION shall not be required to indemnify Customer for any claims or
liabilities arising from Customer' negligence or misconduct. StandardAero
AVIATION shall indemnify, defend, save, and hold harmless Customer and its Parent, subsidiaries, Affiliates and their respective directors, officers,
and employees from and against all claims and liabilities resulting in injuries
or damages suffered by employees of StandardAero in
connection with the performance of Services hereunder.
By Customer . Customer shall indemnify, defend, save, and hold harmless
StandardAero, its Parent, Affiliates, directors, officers,
servants, and employees thereof, from and against any and all
responsibilities, liabilities, claims, demands, suits, judgments, losses,
damages, costs, and expenses for any loss of, damage to, or destruction of
any property (including the Engines) or any injury to or death of any person
arising from Customer' use, operation, repair, maintenance, or disposition of
the Engines; provided, however, Customer shall not be required to
indemnify StandardAero for any claims or liabilities arising
from StandardAero ís negligence or misconduct or breach of
its obligations arising under this Agreement. Customer shall indemnify,
defend, save, and hold harmless StandardAero, its Affiliates,
directors, officers, servants, and employees thereof from and against all
claims and liabilities resulting in injuries or damages suffered by employees
of Customer in connection with the performance of their respective
employment with Customer other than claims arising from injury to the
person resulting from the Services.
Limitation of Liability.
The total liability of StandardAero shall
not exceed the dollar value of the Equipment immediately prior to the
failure precipitating such claim. Neither Party shall be liable for special,
incidental, or consequential damages.
Information, Trademarks.
Unless agreed in writing, any information shared
with each other shall be held in confidence and may not be disclosed to
others. This does not apply to information which is or becomes part of the
general public knowledge other than as a result of breach of any
confidentiality obligation or which was known prior to receipt from the nondisclosing
party. This Agreement does not give either party the right to use the
trademarks of the
Termination.
Either party may terminate this Agreement upon thirty (30)
days written notice for breach of any material provision, unless such breach
is cured within the thirty (30) days. We may terminate this Agreement
without advance notice if you (a) fail to make any of the required payments
when due, (b) make any agreement with your creditors due to your inability
to make timely payment of your debts, (c) enter into compulsory or
voluntary liquidation, (d) become insolvent, or (e) become subject to the
appointment of a receiver of all or a material part of your assets. Upon any
such termination, you will not be relieved of your obligation to pay for
Services performed.
Customer Furnished Material.
Consistent with the approved Workscope
and charges specified in the Proposal, you may supply mutually agreed
quantities and types of parts to us as ìCustomer Furnished Materialî, if
furnished with an Approved Aviation Authority serviceability tag and ready
for immediate use. If your delay in providing material would delay our performance, we may supply such parts and material at your expense.
Dispute Resolution and Governing Law.
This Agreement shall be governed by
the law of the State of Arizona, excluding its conflict of law provisions and the
UN Convention on Contracts for the International Sale of Goods. We will try to
amicably resolve any dispute relating to this Agreement within sixty (60) days. In
the event we do not, the dispute will be settled by binding arbitration in
accordance with the Commercial Arbitration Rules of the American Arbitration
Association in Phoenix, Arizona. Either of us may take appropriate legal action
as may be required for the enforcement of such arbitration award.
General Provisions. Right to Subcontract.
We have the right to subcontract any Service to any
subcontractor properly certified and rated by the Approved Aviation
Authority.
Assignment. This Agreement may not be assigned without the prior written
consent of the other party, except that your consent will not be required for an
assignment by us to one of our affiliates.
Waiver of Immunity. If you are incorporated or based outside the United
States, to the extent that you or any of your property becomes entitled to
sovereign or other immunity from any legal action, you waive your immunity in
connection with this Agreement.
Language, Notices. All correspondence and documentation connected with
this Agreement will be in English. All notices will be in writing, effective
upon receipt and will be provided to the addresses set forth on the Proposal,
which may be changed by written notice.
Non-Waiver of Rights and Remedies. Failure or delay in the exercise of any
right or remedy under this Agreement will not waive or impair such right or
remedy. No waiver given will require future or further waivers.
Entire Agreement. Any portion of this Agreement determined to be
contrary to any controlling law, rule or regulation shall be revised or deleted and the remaining balance of this Agreement will remain in full force
and effect. In the event of a conflict between the Proposal and this document,
the Proposal shall rule. This Agreement may be executed in one or more
counterparts, each treated as the same binding agreement which shall be
effective upon execution.
Proprietary Information of StandardAero